Justia Aerospace/Defense Opinion Summaries

In 2016, a suicide bombing occurred at the U.S. military base in Bagram Airfield, Afghanistan. The bomber, an Afghan national employed by a subcontractor of Fluor Corporation, detonated an explosive vest, injuring Specialist Winston Tyler Hencely, among others. Hencely sued Fluor, alleging negligence in supervision, entrustment, and retention of the bomber, and breach of contract with the U.S. Government.The U.S. District Court for the District of South Carolina granted judgment to Fluor on all claims. The court found that federal law preempted Hencely’s tort claims and that he was not a third-party beneficiary entitled to enforce the Government’s contract with Fluor. Hencely appealed these decisions.The United States Court of Appeals for the Fourth Circuit reviewed the case. The court affirmed the district court’s judgment, holding that the Federal Tort Claims Act’s combatant activities exception preempted Hencely’s state-law tort claims. The court concluded that Fluor was integrated into combatant activities and that the military retained command authority over Fluor’s supervision of Local Nationals at Bagram Airfield. The court also held that Hencely was not an intended third-party beneficiary of the contract between Fluor and the U.S. Government, as the contract did not express an intent to benefit individual soldiers or confer upon them the right to enforce its provisions.Thus, the Fourth Circuit affirmed the district court’s judgment, precluding Hencely’s tort claims and denying his breach of contract claim. View "Hencely v. Fluor Corporation" on Justia Law

Yorktown Systems Group Inc. and Threat Tec LLC, both defense contractors, entered into a mentor-protégé relationship under the Small Business Administration’s program to jointly pursue government contracts. They formed a joint venture (JV) and were awarded a $165 million contract with the U.S. Army. The JV agreement allocated specific work shares to each company. However, the relationship soured, and Threat Tec attempted to terminate Yorktown’s subcontract, effectively cutting Yorktown out of its share of the contract.The United States District Court for the Northern District of Alabama granted Yorktown a preliminary injunction, preventing Threat Tec from terminating the subcontract and depriving Yorktown of its rights under the JV agreement. The court found that Yorktown had shown a substantial likelihood of success on its breach of contract and breach of fiduciary duty claims and faced irreparable harm. The court noted that Threat Tec’s CEO had made false statements and lacked candor, leading to the belief that Threat Tec’s motives were unethical.The United States Court of Appeals for the Eleventh Circuit reviewed the case and affirmed the district court’s decision. The appellate court found no clear error in the district court’s factfindings and concluded that the district court acted within its discretion. The court held that Threat Tec, as the managing member of the JV, owed fiduciary duties of loyalty and care to Yorktown and likely breached those duties by attempting to cut Yorktown out of its contractually specified workshare. The court also agreed that Yorktown faced irreparable harm, including potential damage to its business reputation and the loss of highly skilled employees, which could not be remedied by monetary damages alone. View "Yorktown Systems Group Inc. v. Threat TEC LLC" on Justia Law

For pressing projects, the government can issue “Undefinitized Contract Actions” (UCAs) to allow contractors to begin work before the parties have reached a final agreement on contract terms, like price. The Air Force entered into two UCAs with Lockheed for upgrades to F-16 aircraft. Both UCAs include “definitization” clauses that provide that if the parties are unable to reach agreements on price by a certain time, the Contracting Officer (CO) may determine a reasonable price. After years of negotiations, the Air Force and Lockheed were unable to agree on the price terms. The CO assigned to each UCA unilaterally definitized a price of about $1 billion.The Armed Services Board of Contract Appeals (ASBCA), acting under the Contract Disputes Act (CDA), dismissed appeals for lack of jurisdiction because Lockheed failed to submit a certified contractor claim to the COs requesting a final decision on its claims as required under the CDA. The Federal Circuit affirmed, rejecting Lockheed’s argument that the COs’ unilateral definitizations qualified as government claims under the CDA, which a contractor can directly appeal to the ASBCA without having to submit its own claim to the COs. The COs’ definitizations of the contract prices were not demands or assertions by the government seeking relief against Lockheed. View "Lockheed Martin Aeronautics Co. v. Secretary of the Air Force" on Justia Law

In 2005, the Defense Logistics Agency (DLA) awarded Supreme a contract to provide food to U.S. forces in Afghanistan. During negotiations concerning deliveries to forward operating bases, Supreme submitted inflated cost proposals. Supreme threatened to withhold payments to subcontractors (potentially cutting off supplies to troops), The parties executed a Modification, including Supreme’s proposed rates, subject to verification. The Defense Contract Audit Agency concluded that Supreme’s documentation was not adequate and questioned more than $375 million of claimed costs. The contracting officer, in 2011, determined that DLA had overpaid Supreme by $567,267,940. DLA withheld $540 million from Supreme’s monthly payments. Supreme submitted unsuccessful “reverse image” claims. In 2014, Supreme pled guilty to fraud and entered into a civil settlement in a False Claims Act suit. During the investigations, with Supreme’s contract expiring, the parties entered into two extensions. In 2015, based on Supreme’s guilty plea, DLA demanded the return of all money paid under the contract. In 2020, the Armed Services Board of Contract Appeals concluded that Supreme’s contract claims against the government were barred by Supreme’s prior material breach.The Federal Circuit affirmed. The government did not waive its prior material breach defense. While DLA had some notice of Supreme’s fraudulent behavior in 2009, it had no “known right” until Supreme’s guilty plea, after which DLA never extended Supreme’s contract. Supreme cannot treat the bridge contracts as separate only to evade the government’s affirmative defenses. The parties treated the original contract and the extensions as inextricably intertwined; DLA’s prior material breach defense applies to those contracts. View "Supreme Foodservice GmbH v. Director of the Defense Logistics Agency" on Justia Law

The Defense Supply Center Philadelphia (DSCP), a sub-agency of the Defense Logistics Agency, issued a solicitation for an Indefinite-Delivery/Indefinite-Quantity commercial item contract to provide food and non-food products to customers, including the military, in three overseas zones. In May 2003, DSCP awarded a contract to Agility to supply “Full Line Food and Non-Food Distribution” to authorized personnel in Kuwait and Qatar. After many modifications, in December 2005, Agility submitted a Request for Equitable Adjustment for $13.1 million related to trucks being held in Iraq by the government for longer than 29 days. In April 2007, the government’s contracting officer denied Agility’s claim. The Armed Services Board of Contract Appeals denied Agility’s appeal in August 2015, finding that Agility had accepted all risks associated with delays beyond 29 days. The Board stated that it “need not decide whether the government constructively changed contract performance or whether it breached its implied duty of cooperation” because “whether the government breached the contract comes down to contract interpretation.” The Federal Circuit affirmed-in-part, agreeing that the government did not breach the express terms of the contract or a later agreement to consider exceptions, but finding that the Board erred when it concluded that it “need not decide” Agility’s implied duty and constructive change claims. View "Agility Public Warehousing Co. KSCP v. Mattis" on Justia Law

Plaintiffs, employed by defense contractor Qinetiq to work on a military base in Iraq, were enrolled in Qinetiq’s Basic Long Term Disability, Basic Life, and Accidental Death and Dismemberment insurance policies, governed by the Employee Retirement Income Security Act (ERISA), 29 U.S.C. 1001, under a single contract with Prudential. Qinetiq paid the premiums. Plaintiffs also purchased, with their own funds, supplemental coverage under the same terms as the basic policies; there was a single summary plan description. An employee would file a single claim for basic and supplemental coverage benefits. The plan booklets provided that loss is not covered if it results from war, or any act of war, declared or undeclared. These exclusions applied to both the basic and supplemental policies. The plaintiffs were not otherwise uninsured for excluded injuries. Qinetiq obtained insurance required by the Defense Base Act, 42 U.S.C. 1651. After Prudential denied claims, the plaintiffs sued, alleging violations of the state consumer fraud acts and the Truth in Consumer Contract, Warranty, and Notice Act; breach of contract and breach of the implied covenant of good faith and fair dealing; and intentional or negligent misrepresentation or omission. They contended that Prudential fraudulently induced them to buy supplemental coverage knowing that any claim they filed would likely be subject to the war exclusions, rendering supplemental coverage effectively worthless. The district court dismissed, treating the basic and supplemental policies as components of a single plan, and holding that all state law claims were preempted by ERISA. The Third Circuit affirmed, holding that the supplemental coverage cannot be “unbundled” from ERISA coverage. View "Menkes v. Prudential Ins. Co. of Am." on Justia Law

Following the 1941 attack on Pearl Harbor, each of the Oil Companies entered into contracts with the government to provide high-octane aviation gas (avgas) to fuel military aircraft. The production of avgas resulted in waste products such as spent alkylation acid and “acid sludge.” The Oil Companies contracted to have McColl, a former Shell engineer, dump the waste at property in Fullerton, California. More than 50 years later, California and the federal government obtained compensation from the Oil Companies under the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA), 42 U.S.C. 9601, for the cost of cleaning up the McColl site. The Oil Companies sued, arguing the avgas contracts require the government to indemnify them for the CERCLA costs. The Court of Federal Claims granted summary judgment in favor of the government. The Federal Circuit reversed with respect to breach of contract liability and remanded. As a concession to the Oil Companies, the avgas contracts required the government to reimburse the Oil Companies for their “charges.” The court particularly noted the immense regulatory power the government had over natural resources during the war and the low profit margin on the avgas contracts. View "Shell Oil Co. v. United States" on Justia Law

Appellant guaranteed CWA obligations under an Aircraft Management Agreement (AMA) between CWA and BP. BP sued CWA and appellant for breach of contract. The district court denied appellant's motion for summary judgment and granted summary judgment to BP on its claims that appellant was liable under the guaranty for CWA's breach of the AMA. Appellant appealed. The court held that the district court did not err in concluding CWA waived any conceivable right to rescind it might have had; BP's consideration for the AMA was sufficient; CWA's performance was not excused; and the district court did not err in holding appellant liable for the paint and refurbishment costs. Because genuine disputes remained as to whether the AMA and Priester agreement were substantially similar and whether BP otherwise took reasonable steps to avoid unnecessary damages, the court reversed the district court's judgment. The court expressed no opinion as to whether appellant had waived his present-value argument. View "BP Group, Inc. v. Kloeber, Jr." on Justia Law

In a national emergency, the Department of Defense can augment its own capabilities with aircraft drawn from the "Civil Reserve Air Fleet," composed of aircraft owned by commercial carriers but committed voluntarily for use during emergencies. The Fleet is divided into teams of airlines. The Department awards mobilization value points; the more points a member has, the more non-emergency Department air transportation the member can bid on. Points are transferrable within teams. Members of defendant's team have a contract with a one-year term and a separate three-year agreement concerning distribution of business among members. Plaintiff's suit is based on a 2006 three-year agreement in the form of a letter. A change from what members of the team had been doing ultimately led to plaintiff's withdrawal from the team. Plaintiff subsequently went into bankruptcy. Plaintiff won a jury verdict of almost $66 million. The Seventh Circuit reversed, holding that the "agreement" did not include crucial terms and was so indefinite as to be unenforceable. The court also criticized the regression analysis on which the award was calculated. A promissory estoppel claim, while not preempted, failed on the facts. View "ATA Airlines, Inc. v. FedEx Corp." on Justia Law

After petitioners fell behind schedule in developing a stealth aircraft (A-12) for the Navy, the contracting officer terminated their $4.8 billion fixed-price contract for default and ordered petitioners to repay approximately $1.35 billion in progress payments for work the Government never accepted. Petitioners filed suit in the Court of Federal Claims ("CFC"), challenging the termination decision under the Contract Disputes Act of 1978, 41 U.S.C. 609(a)(1). The CFC held that, since invocation of the state-secrets privilege obscured too many of the facts relevant to the superior-knowledge defense, the issue of that defense was nonjusticiable, even though petitioners had brought forward enough unprivileged evidence for a prima facie showing. Accordingly, at issue was what remedy was proper when, to protect state secrets, a court dismissed a Government contractor's prima facie valid affirmative defense to the Government's allegations of contractual breach. The Court concluded that it must exercise its common-law authority in this situation to fashion contractual remedies in Government-contracting disputes and held that the proper remedy was to leave the parties where they were on the day they filed suit. View "General Dynamics Corp. v. United States; The Boeing Co. v. United States" on Justia Law