Justia Aerospace/Defense Opinion Summaries

The Court of Federal Claims enjoined the U.S. Army from proceeding with, or awarding, a contract to Airbus Helicopter, finding that Army Execution Order 109-14, which implemented the Army’s Aviation Restructure Initiative designating the UH-72A Lakota helicopter as the Army’s “Institutional Training Helicopter,” was a procurement decision in violation of the Competition in Contracting Act and the Federal Acquisition Regulation. The court also found the Sole Source Justification and Approval (J&A) was arbitrary and capricious. The Federal Circuit reversed and vacated the injunction, holding that Execution Order 109-14 was not a procurement decision subject to Tucker Act review because it did not begin “the process for determining a need for property or services.” The Order simply formalized the Army’s decision designating the UH-72A Lakota as the Army’s training helicopter. The Sole Source J&A was not arbitrary and capricious, and it was an abuse of discretion to supplement the administrative record. The J&A sufficiently supports the Army’s decision to award a sole-source follow-on contract because it is likely that award to any other source would result in substantial duplication of cost to the government that is not expected to be recovered through competition, or unacceptable delays in fulfilling the agency’s requirements.” View "AgustaWestland North America v. United States" on Justia Law

Tightened security at base, preventing access by contractor's ex-felon employees, did not justify contract adjustment. Malmstrom Air Force Base in Great Falls, Montana, houses intercontinental ballistic missiles. Garco's contract to construct base housing incorporated Federal Acquisition Regulation 52.222-3, providing that contractors may employ ex-felons and requiring contractors to adhere to the base access policy. Malstrom’s access policy indicated that it would run the employees’ names through the National Criminal Information Center. “Unfavorable results will be scrutinized and eligibility will be determined on a case-by-case basis.” Garco’s subcontractor, JTC, experienced difficulty bringing its crew onto the base. JTC used workers from a local prison’s pre-release facility. JTC had not encountered access problems in its performance of other Malmstrom contracts over the preceding 20 years. Security had been tightened after an incident where a prerelease facility worker beat his manager. JTC requested an equitable adjustment of the contract, stating that its inability to use convict labor greatly reduced the size of the experienced labor pool so that it incurred $454,266.44 of additional expenses; JTC did not request a time extension. The Federal Circuit affirmed the Armed Services Board of Contract Appeals’ denial of the claim, rejecting a claim of constructive acceleration of the contract. The court concluded that there was no change to the base access policy. View "Garco Construction, Inc. v. Secretary of the Army" on Justia Law

The Defense Supply Center Philadelphia (DSCP), a sub-agency of the Defense Logistics Agency, issued a solicitation for an Indefinite-Delivery/Indefinite-Quantity commercial item contract to provide food and non-food products to customers, including the military, in three overseas zones. In May 2003, DSCP awarded a contract to Agility to supply “Full Line Food and Non-Food Distribution” to authorized personnel in Kuwait and Qatar. After many modifications, in December 2005, Agility submitted a Request for Equitable Adjustment for $13.1 million related to trucks being held in Iraq by the government for longer than 29 days. In April 2007, the government’s contracting officer denied Agility’s claim. The Armed Services Board of Contract Appeals denied Agility’s appeal in August 2015, finding that Agility had accepted all risks associated with delays beyond 29 days. The Board stated that it “need not decide whether the government constructively changed contract performance or whether it breached its implied duty of cooperation” because “whether the government breached the contract comes down to contract interpretation.” The Federal Circuit affirmed-in-part, agreeing that the government did not breach the express terms of the contract or a later agreement to consider exceptions, but finding that the Board erred when it concluded that it “need not decide” Agility’s implied duty and constructive change claims. View "Agility Public Warehousing Co. KSCP v. Mattis" on Justia Law

Within the Department of Defense, DRMS disposes of surplus military property at Defense Reutilization and Marketing Offices (DRMOs). Property that cannot be reutilized is demilitarized and/or reduced to scrap that can be sold. A 2007 DRMS Request for Proposals sought performance of DRMO activities for up to five years. A referenced website showed DRMS’s historical workload and scrap weight; an amendment indicated that “the contractor may experience significant workload increases or decreases” and outlined a process to “renegotiate the price” if workload increased. DRMS awarded its first contract to Agility to operate six DRMOs for one base year with four option years at a fixed price of $45,233,914.92 per year. Upon commencing work in Arifjan, the largest of the DRMOs, Agility immediately fell behind. It inherited a backlog of approximately 30 weeks. From the start, the volume received at Arifjan was greater than Agility anticipated. The parties terminated their contract for convenience in 2010. Agility thereafter requested funding for its additional costs, claiming DRMS provided inaccurate workload estimates during solicitation. The contracting officer awarded Agility only $236,363.93 for its first claim and nothing for the second, noting that Agility received an offset from its scrap sales. The Federal Circuit reversed, as “clearly erroneous,” the Claims Court’s findings that DRMS did not inadequately or negligently prepare its estimates and that Agility did not rely on those estimates. Agility’s receipt of scrap sales and the parties’ agreement did not preclude recovery. View "Agility Defense & Government Services, Inc. v. United States" on Justia Law

Kase was exposed to asbestos insulation used on nuclear submarines during the early 1970s. The trial court rejected claims against a broker that arranged for asbestos-containing insulation to be shipped to the Mare Island Naval Shipyard, where workers packed it around the submarine piping it protected. The court held, on summary judgment, that the Navy‘s procurement of asbestos insulation for its nuclear submarines implicated the government contractor defense set forth in the Supreme Court’s 1988 holding, Boyle v. United Technologies Corp. The broker procured the insulation pursuant to and in compliance with relatively detailed performance and testing specifications, although those specifications did not expressly call out for asbestos in the insulation. According to undisputed evidence, the specifications could only be met by asbestos-containing insulation, and the only product on the Navy‘s approved list of suitable products was the product at issue, Unibestos. The court of appeal affirmed, stating that the defense does not necessarily exclude the procurement of products also sold commercially. The Navy‘s procurement of the asbestos insulation at issue occurred after years of evaluating and weighing the utility of and the health hazards associated with asbestos products and pursuant to specifications that required an asbestos product. View "Kase v. Metalclad Insulation Corp." on Justia Law

Papp alleged that his late wife suffered secondary “take home” asbestos exposure while washing the work clothes of her first husband, Keck. Keck had several jobs that exposed him to asbestos. Papp sued multiple companies in New Jersey. In a deposition, he indicated that the landing gear Keck sandblasted was for a C-47 military cargo plane, built by Boeing’s predecessor. Boeing removed the case, citing the federal officer removal statute, 28 U.S.C. 1442(a)(1). Boeing asserted that it was entitled to government contractor immunity because the C-47 was produced for, and under the specific supervision of, the U.S. military and that the supervision extended to labels and warnings for all parts of the aircraft, including those parts laden with the asbestos to which Keck would later be exposed. The district court remanded, reasoning that Boeing, as a contractor and not a federal officer, had a “special burden” to demonstrate “that a federal officer or agency directly prohibited Boeing from issuing, or otherwise providing, warnings as to the risks associated with exposure to asbestos contained in products on which third-parties … worked or otherwise provided services.” The Third Circuit reversed, holding that the statute extends to contractors who possess a colorable federal defense and that Boeing made a sufficient showing of such a defense. View "Papp v. Fore-Kast Sales Co Inc" on Justia Law

Zafer, an Ankara, Turkey, contractor, and the Army Corps of Engineers (USACE) entered into a firm-fixed-price contract to construct the MILCON Support Facility at the Bagram Air Force Field in Afghanistan. Zafer was responsible for delivering materials to the site, and assumed the risk “for all costs and resulting loss or profit.” After issuing notice to proceed, USACE recognized that it could not make the project site available immediately and increased the contract price and set a new completion date. In November 2011, Pakistan closed its border from the seaport city of Karachi along the land routes into Afghanistan in response to a combat incident with the U.S. and NATO. The route remained closed for 219 days, Zafer notified USACE that the closure would greatly impact its delivery of materials and requested direction on how to proceed. USACE replied that the closure was “purely the act of Pakistan governmental authorities,” that the U.S. government was “not responsible” and denied further compensation. Zafer subsequently, repeatedly, asked for payment for additional costs. In 2013, Zafer submitted an unsuccessful request for an equitable adjustment. The contracting officer found no evidence supporting a constructive change claim. The Claims Court granted USACE summary judgment. The Federal Circuit affirmed. Zafer failed to designate specific facts to establish a constructive change claim based on either a constructive acceleration theory or on a government fault theory. View "Zafer Taahhut Insaat v. United States" on Justia Law

Plaintiffs, Woodward employees, filed a qui tam action under the False Claims Act, alleging that Woodward falsely certified helicopter engine parts that it sold to the government. Plaintiffs had complained that the sensors at issue did not meet quality standards and had refused to work on the order. Following an investigation, a Defense Contract Management Agency Technical Specialist concluded that there was “nothing either incorrect or wrong with the procedures, assembly, or testing of the sensors.” The government continues to order, pay for, and use Woodward’s sensor The Seventh Circuit affirmed summary judgment in favor of Woodward, agreeing that even if Woodward made false statements to the government, no reasonable jury could find that it made the statements knowingly or that the statements were material. View "Marshall v. Woodward, Inc." on Justia Law

The U.S. Air Force solicited bids from private companies to supply equipment and services to build a new radar system. Raytheon, Northrop Grumman, and Lockheed Martin cleared early hurdles; each received a solicitation for proposals for Engineering and Manufacturing Development. The Air Force subsequently sent Evaluation Notices to Raytheon and Northrop that “contractors would not be permitted to use IR & D costs to reduce their costs of performing . . . if those costs were implicitly or explicitly required for contract performance.” Raytheon objected; Northrop did not.. The Air Force then changed its view and accepted Raytheon’s treatment of certain costs as IR & D costs, but never communicated its new view to Northrop. In final proposals, Raytheon proposed IR & D cost reductions, whereas Northrop did not. The Air Force awarded the contract to Raytheon. Northrop and Lockheed filed protests with the Government Accountability Office (31 U.S.C. 3551). In response, the Air Force “decided to take corrective action” and to reopen discussions. Raytheon filed a protest under 28 U.S.C. 1491(b) to challenge the decision to take corrective action. The Federal Circuit affirmed denial of the protest, concluding that the reopening decision was proper based on the disparate-information violation. View "Raytheon Co. v. United States" on Justia Law

Astornet alleges that it is sole exclusive licensee and owner of all rights in the 844 patent, issued in 2009 to Haddad as the inventor and entitled “Airport vehicular gate entry access system” and asserted the patent against NCR, MorphoTrust USA, and BAE Astornet alleged that the three had contracts with the Transportation Security Administration (TSA) to supply boarding-pass scanning systems; that TSA’s use of the equipment infringed and would infringe the patent; and that NCR and MorphoTrust were bidding for another contract to supply modified equipment whose use by TSA would also infringe. The Federal Circuit affirmed dismissal, finding that Astornet’s exclusive remedy for the alleged infringement was a suit against the government in the Court of Federal Claims under 28 U.S.C. 1498. View "Astornet Techs., Inc. v. BAE Sys., Inc." on Justia Law