After petitioners fell behind schedule in developing a stealth aircraft (A-12) for the Navy, the contracting officer terminated their $4.8 billion fixed-price contract for default and ordered petitioners to repay approximately $1.35 billion in progress payments for work the Government never accepted. Petitioners filed suit in the Court of Federal Claims ("CFC"), challenging the termination decision under the Contract Disputes Act of 1978, 41 U.S.C. 609(a)(1). The CFC held that, since invocation of the state-secrets privilege obscured too many of the facts relevant to the superior-knowledge defense, the issue of that defense was nonjusticiable, even though petitioners had brought forward enough unprivileged evidence for a prima facie showing. Accordingly, at issue was what remedy was proper when, to protect state secrets, a court dismissed a Government contractor's prima facie valid affirmative defense to the Government's allegations of contractual breach. The Court concluded that it must exercise its common-law authority in this situation to fashion contractual remedies in Government-contracting disputes and held that the proper remedy was to leave the parties where they were on the day they filed suit.
Posted in: Aerospace/Defense, Contracts, Government & Administrative Law, Government Contracts, U.S. Supreme Court